Free Professional Contractor Scope of Work

Prepared by: [YOUR NAME]
Date: August 25, 2050

Introduction

This Scope of Work (SOW) outlines the detailed work requirements for the construction project between [YOUR COMPANY NAME] and Harrell Properties Ltd. The purpose of this document is to clearly define the tasks, responsibilities, materials, timelines, and deliverables associated with the construction of Harrell Commercial Plaza. This SOW will guide both parties in understanding the expectations and ensuring the project is completed according to agreed specifications, budget, and schedule.

• Project Title: Construction of Harrell Commercial Plaza

• Project Location: 7812 North Maplewood Avenue, San Francisco, CA

• Project Start Date: September 1, 2050

• Project End Date: December 20, 2050

Scope of Work Overview

1. Project Description

The contractor will provide labor, materials, equipment, and management necessary for the construction of Harrell Commercial Plaza. This includes site preparation, foundation work, structural building, utilities installation, and final finishing according to the architectural and engineering specifications provided by Harrell Properties Ltd.

2. Deliverables

The deliverables for this project include the following:

• Site Preparation: Clear and grade the site by September 10, 2050.

• Foundation: Complete excavation and foundation work by September 25, 2050.

• Framing and Structural Work: Finish the structural framework by October 20, 2050.

• Electrical and Plumbing: Install all wiring, electrical systems, and plumbing by November 5, 2050.

• Final Finishing: Complete all finishing work (painting, flooring, etc.) by December 15, 2050.

Responsibilities

Schedule and Milestones

The contractor is expected to adhere to the following milestones and completion dates:

• Site Preparation: Complete by September 10, 2050

• Foundation Work: Complete by September 25, 2050

• Structural Work: Complete by October 20, 2050

• Utilities Installation (Electrical and Plumbing): Complete by November 5, 2050

• Exterior Work: Complete by November 20, 2050

• Interior Finishing: Complete by December 15, 2050

• Final Inspection and Handover: December 20, 2050

Payment Terms

Payments will be made in installments based on the completion of key milestones:

1. Initial Payment (20%): Upon signing the contract and before the start of site preparation.

2. Second Payment (20%): Upon completion of the foundation work.

3. Third Payment (20%): Upon completion of structural framing.

4. Fourth Payment (20%): Upon completion of electrical and plumbing installation.

5. Final Payment (20%): Upon final inspection and project handover.

Terms and Conditions

1. Change Orders: Any changes to the Scope of Work will require a written change order signed by both [YOUR COMPANY NAME] and Harrell Properties Ltd.

2. Warranties: The contractor will provide a 5-year warranty on all labor and materials used in the project.

3. Site Access: The contractor will have access to the site during regular business hours unless otherwise agreed upon with Harrell Properties Ltd.

4. Safety Compliance: All work will comply with San Francisco building safety regulations.

5. Dispute Resolution: Any disputes arising from this agreement will be resolved through binding arbitration.

Contact Information

Prepared by: [YOUR NAME]
Title: [YOUR TITLE]
Company: [YOUR COMPANY NAME]
Phone: [YOUR COMPANY NUMBER]
Email: [YOUR EMAIL]
Address: [YOUR COMPANY ADDRESS]
Website: [YOUR COMPANY WEBSITE]
Social Media: [YOUR COMPANY SOCIAL MEDIA]

Scope of Work Templates @ Template.net