Free School Development Agreement

I. The Parties

This School Development Agreement ("Agreement") is made and entered into on [Month Day, Year] ("Effective Date") by and between [Your Company Name] hereinafter referred to as the ("School") with a primary place of business at [Your Company Address] and [Developer's Name] hereinafter referred to as the ("Developer") with a primary place of business at [Developer's Address] collectively referred to as the ("Parties").

WHEREAS, the School desires to develop and expand its educational facilities to better serve its students and community;

WHEREAS, the Developer possesses the necessary qualifications, experience, and expertise to undertake such development projects;

WHEREAS, the Parties wish to set forth the terms and conditions under which the development of the School's facilities will be carried out;

NOW THEREFORE, in consideration of the mutual covenants and promises herein contained, the Parties hereby agree as follows:

II. Scope of Work

A. Project Description

1. Design and Construction: The Developer shall design and construct the new school buildings in accordance with the specifications provided by the School. This includes classrooms, laboratories, administrative offices, and recreational facilities.

2. Compliance and Safety: All construction must adhere to applicable building codes and safety regulations to ensure the safety and functionality of the facilities.

3. Landscaping and Parking: The project will also encompass landscaping and the construction of parking lots as specified by the School to enhance the overall campus environment.

4. Amendments: Any amendments to the scope of work must be agreed upon in writing by both Parties to ensure clarity and mutual understanding.

B. Timeline

1. Project Commencement and Completion: The project shall commence on [Month Day, Year] and is expected to be completed by [Month Day, Year]. Adhering to this timeline is crucial for project success.

2. Delay Communication: Any delays in the project timeline must be communicated immediately to the School by the Developer to facilitate prompt resolution and adjustments.

3. Progress Reports: The Developer shall provide monthly progress reports to the School to keep all stakeholders informed of the project's status.

4. Penalties for Delay: Penalties for delay in project completion will be as per the terms outlined in Section VIII to ensure accountability and adherence to the timeline.

C. Deliverables

1. Architectural Drawings and Blueprints: The Developer shall provide detailed architectural drawings and blueprints by [Month Day, Year] to ensure the project starts with a clear and approved plan.

2. Construction Reports: Regular construction reports and updates shall be provided at intervals agreed upon between the Parties to track progress and address any issues.

3. Final Project Report: Upon completion, the Developer shall deliver a final project report, including all material specifications, warranties, and manuals to provide a comprehensive overview of the project.

4. As-Built Drawings: All as-built drawings must be submitted to the School within [30] days of project completion to ensure accurate records of the completed work.

III. Responsibilities of the School

A. Payments

1. Total Payment Amount: The School agrees to pay the Developer a total amount of [$3,000,000.00] for the development project, ensuring adequate funding for the project's scope.

2. Installment Payments: Payments will be made in installments based on project milestones to facilitate financial planning and progress tracking.

3. Initial Payment: The School shall make the initial payment of [$500,000.00] within [10] days of executing this Agreement to enable the Developer to commence work.

4. Final Payment: The final payment will be made upon project completion and acceptance of the deliverables by the School to ensure all work meets the agreed standards.

5. Withholding Payments: The School reserves the right to withhold payment if the Developer fails to meet the agreed project milestones or quality standards to ensure accountability.

B. Access and Approvals

1. Site Access: The School shall provide the Developer with full access to the construction site throughout the duration of the project to facilitate uninterrupted work.

2. Permits and Approvals: The School will secure all necessary permits and approvals required for the construction to ensure legal compliance.

3. Delay Communication: Any delay in providing site access or necessary approvals shall be promptly communicated to the Developer to allow for timely adjustments.

4. Inspections and Assessments: The School will facilitate scheduled inspections and quality assessments as required by local authorities to ensure compliance and quality.

C. Communication

1. Project Manager: The School shall designate a project manager to act as the primary point of contact for the Developer, ensuring clear and consistent communication.

2. Written Instructions: All instructions and feedback from the School must be provided in writing to ensure clarity and traceability.

3. Monthly Meetings: Monthly meetings shall be held between the Parties to review progress and address any issues, fostering collaboration and transparency.

IV. Responsibilities of the Developer

A. Compliance

1. Legal Compliance: The Developer shall ensure that all work complies with applicable federal, state, and local laws and regulations to avoid legal issues and ensure project integrity.

2. Safety and Quality Standards: All construction shall adhere to the safety and quality standards as specified in the project documents to ensure the safety and functionality of the facilities.

3. Correcting Violations: Any violations of compliance must be corrected at the Developer's expense to maintain project standards and legality.

4. Subcontractor Licenses: The Developer will obtain all required subcontractor licenses and certifications to ensure qualified and compliant workforce.

B. Insurance

1. Adequate Coverage: The Developer shall maintain adequate insurance coverage for the duration of the project, including general liability insurance and worker's compensation, to mitigate risks.

2. Certificates of Insurance: Certificates of insurance shall be provided to the School prior to the commencement of work to ensure proof of coverage.

3. Subcontractor Insurance: The Developer shall ensure that all subcontractors also maintain adequate insurance coverage to protect all parties involved.

C. Materials and Labor

1. Procurement Responsibilities: The Developer is responsible for procuring all materials, labor, equipment, and tools necessary for the completion of the project, ensuring the timely availability of resources.

2. Material Compliance: All materials used must comply with the specifications provided by the School to ensure quality and consistency.

3. Accountability for Defects: The Developer shall be accountable for any damages or defects arising due to substandard materials or workmanship, ensuring corrective measures are taken.

4. Warranties: Warranties for materials and workmanship shall be provided as specified in the project documents to ensure long-term quality and reliability.

V. Payment Terms

A. Payment Schedule

1. Timely Payments: Payments due upon completion of milestones must be paid within [15] business days upon receipt of an invoice from the Developer to ensure cash flow for ongoing work.

2. Evidence of Completion: Invoices must be accompanied by evidence of milestone completion as specified in the payment schedule to validate the work done.

3. Milestone Requirements: The Developer's failure to meet milestone requirements can lead to delayed or withheld payments to ensure adherence to the project plan.

B. Adjustments and Changes

1. Documented Changes: Any changes to the project scope requiring additional payments must be documented and approved by both Parties to ensure clarity and mutual consent.

2. Cost Savings: Changes resulting in cost savings shall be credited back to the School to reflect the adjusted project expenses.

3. Additional Costs Notification: Should unforeseen circumstances arise that necessitate additional costs, the Developer must notify the School as soon as possible to discuss adjustments.

VI. Project Timeline

A. Schedule

1. Detailed Schedule: The Developer must provide a detailed construction schedule within [15] days of the Agreement's Effective Date to outline the project's timeline.

2. Deviations and Approvals: Any deviations from the project schedule must be communicated and approved by the School to ensure alignment and transparency.

3. Responsibility for Schedule: The Developer is responsible for ensuring that the project stays on schedule, taking necessary actions to address any delays.

B. Delays

1. Unforeseen Circumstances: In the event of delays caused by unforeseen circumstances, the Developer must inform the School immediately to allow for prompt adjustments.

2. Mitigation Efforts: The Parties will work together to mitigate any delays and adjust the project schedule accordingly to minimize impact.

3. Delay Documentation: All delays and their causes must be documented and discussed to ensure transparency and accountability.

C. Inspection and Approval

1. Regular Inspections: The School shall conduct regular inspections to ensure compliance with the project specifications and schedule, maintaining quality and standards.

2. Final Inspection: Final inspection and approval by the School are required before project completion to ensure all work meets the agreed standards.

3. Addressing Issues: The Developer must address any issues raised during inspections promptly to maintain project integrity and satisfaction.

VII. Termination

A. Termination by School

1. Right to Terminate: The School reserves the right to terminate this Agreement upon [30] days' written notice if the Developer fails to comply with the terms and conditions, ensuring accountability.

2. Effective Termination: Termination shall be effective immediately upon the Developer's receipt of written notice specifying the grounds for termination to ensure clarity and prompt action.

3. Post-Termination Actions: Upon termination, the Developer shall cease all work and return any materials, documents, or property belonging to the School to ensure proper closure.

B. Termination by Developer

1. Grounds for Termination: The Developer may terminate this Agreement upon [30] days' written notice if the School fails to make timely payments as specified in this Agreement, ensuring financial fairness.

2. Notice of Default: Termination by the Developer must be preceded by a written notice of default and an opportunity for the School to remedy the default within a specified period to allow for resolution.

3. Compensation for Work Completed: Upon termination, the School shall compensate the Developer for work completed up to the effective termination date to ensure fair payment for services rendered.

C. Mutual Termination

1. Mutual Agreement: Both Parties may mutually agree to terminate this Agreement in writing at any time to allow for a consensual and amicable termination.

2. Outstanding Obligations: All outstanding obligations and payments shall be settled as per the mutually agreed terms upon termination to ensure clarity and fairness.

3. Post-Termination Settlement: All financial and material settlements shall be concluded promptly to facilitate a smooth and fair termination process.

VIII. Penalties and Liabilities

A. Penalties for Delay

1. Penalty Amount: Penalties for delays not caused by the School shall be as follows: [$3,000] per day beyond the agreed project completion date to ensure timely completion.

2. Penalty Cap: The total penalty amount shall not exceed [10]% of the total project cost to ensure proportionality and fairness.

3. Exemptions: Delays caused by weather, natural disasters, or other unforeseen events shall not incur penalties to ensure fairness in uncontrollable circumstances.

4. Penalty Deductions: Penalties shall be deducted from the final payment due to the Developer to ensure accountability and adherence to the timeline.

B. Liability for Defects

1. Defects Liability Period: The Developer shall be liable for any defects in materials or workmanship that arise within [1] year after project completion to ensure quality and durability.

2. Correction of Defects: All defects must be corrected promptly at the Developer's expense upon notification by the School to maintain project standards.

3. Additional Penalties: Failure to correct defects in a timely manner may result in additional penalties to ensure prompt and effective resolution.

4. Reimbursement for Damages: The School reserves the right to seek reimbursement for any damages caused by such defects to ensure accountability and quality.

IX. Dispute Resolution

A. Mediation

1. Initial Resolution Attempt: In the event of a dispute, the Parties agree to first attempt to resolve the issue through mediation to ensure a fair and amicable resolution.

2. Mediator Selection: Mediation shall be conducted by a neutral third-party mediator agreed upon by both Parties to ensure impartiality.

3. Cost Sharing: The costs of mediation shall be shared equally between the Parties to ensure fairness in resolving disputes.

B. Arbitration

1. Binding Arbitration: If mediation fails, the dispute shall be resolved by binding arbitration in accordance with the rules of the [American Arbitration Association] to ensure a definitive resolution.

2. Arbitration Location and Language: The arbitration shall take place in [State Name] and shall be conducted in the English language to ensure clarity and accessibility.

3. Final and Binding Decision: The arbitrator's decision shall be final and binding, and judgment upon the award may be entered into any court having proper jurisdiction to ensure enforceability.

C. Legal Fees

1. Recovery of Legal Fees: In the event of any legal action to enforce or interpret this Agreement, the prevailing party shall be entitled to recover its reasonable attorney's fees and costs to ensure fairness.

2. Survival of Provision: This provision shall survive the termination of this Agreement to ensure its enforceability in case of disputes.

X. Governing Law

A. Jurisdiction

1. Governing Law: This Agreement shall be governed by and construed in accordance with the laws of the State of [State Name], without regard to its conflict of law principles to ensure legal clarity.

2. Exclusive Jurisdiction: Any legal action arising out of or related to this Agreement shall be brought exclusively in the state or federal courts located in [State Name] to ensure jurisdictional clarity.

B. Compliance with Laws

1. Legal Compliance: The Developer agrees to comply with all applicable federal, state, and local laws and regulations in the performance of its obligations under this Agreement to ensure legal adherence.

2. Material Breach: Any failure by the Developer to comply with such laws and regulations shall be considered a material breach of this Agreement to ensure accountability.

XI. Signatures

IN WITNESS WHEREOF, the Parties hereto have executed this Development Agreement as of the Effective Date.

School

[Authorized Representative Name]

[Your Company Name]

Date: [Month Day, Year]

Developer

[Authorized Representative Name]

[Developer's Name]

Date: [Month Day, Year]

School Templates @ Template.net